Construction stop? Here’s how to master construction disruptions according to VOB!
Hand on heart: A construction disruption according to VOB is certainly a nightmare for everyone in construction at first. But don’t worry, with the right know-how and a smart approach, you can overcome this hurdle as well. That’s exactly why we wrote this article – it is meant to be your personal guide to understand the pitfalls of a construction disruption according to VOB to safeguard your rights as a contractor or client and avoid costly mistakes. Here at Valoon GmbH, we know from experience how invaluable clear communication and comprehensive construction documentation are, especially when it comes to critical issues like a disruption. We show you how to secure your claims with correct notifications and strategic skill, contributing to a smooth project workflow. Our goal? To provide you not only with dry theory but also practical tips so you can remain confident in such situations.
- Understanding the complexity of a construction disruption according to VOB construction disruption.
- Effectively secure your rights as a contractor or client.
- Avoid costly mistakes through correct procedures.
- Recognize the importance of clear communication and comprehensive construction documentation documentation.
What exactly is a construction disruption according to VOB/B?
So, what does the term actually conceal? construction disruption according to VOB? Simply put: These are circumstances that prevent you as a contractor, without your fault, from delivering your contractually agreed construction services on time or as planned. The German Construction Contract Procedures, Part B (VOB/B), and particularly § 6 VOB/B, serve as our legal anchor – provided, of course, that it is effectively incorporated into the construction contract. Such a disruption can take many forms: delayed pre-services from other trades, unforeseen weather chaos, and much more. It is always important: The disruption must not originate from your own area of responsibility as a contractor. The right handling of a construction disruption according to VOB is crucial for a possible extension of deadlines and potential claims for damages. A clear definition and distinction are therefore the first, crucial steps in managing the consequences of such a disruption.Paragraph jungle? Your compass for § 6 VOB/B & BGB in case of construction disruptions.
So that everything is fair in a construction disruption according to VOB construction project, we need clear rules of the game – and these are found in the legal foundations. They are extremely important for both parties, contractors and clients, as they define what happens when the construction process comes to a halt. Those who know these regulations well, especially § 6 VOB/B, can act legally secure during such a disruption and protect themselves from financial disadvantages. And even if the VOB/B isn’t explicitly stated in the contract, certain principles can also play a role in BGB contracts. This once again shows how essential clean contract design is from the very beginning.
- Understanding the legal foundations (VOB/B, BGB) as fair rules of the game.
- Acting legally secure through knowledge of § 6 VOB/B and warding off financial disadvantages.
- Considering the possible relevance of VOB/B principles even in BGB contracts.
- Recognizing the importance of clean contract design from the start.
VOB/B § 6: The heart of construction disruptions.
When it comes to the construction disruption according to VOB , § 6 VOB/B is basically the focal point. It precisely stipulates which conditions apply, the consequences of a disruption, and what obligations contractors and clients have. One of the most important obligations for you as a contractor is the immediate written notification of the disruption to the client. In this, you must state the reasons and the expected impact. If VOB/B isn’t effectively anchored in the contract, the rules of the Civil Code (BGB) come into play first. But beware: Courts, such as the BGH, often refer to the principles of § 6 VOB/B even in BGB contracts – particularly regarding notification obligations and risk distribution in a disruption. Correctly applying § 6 VOB/B is therefore absolutely critical for any construction disruption according to VOB disruption.
Construction disruption in BGB contracts: What applies?
But what if the VOB/B is not part of the contract at all? In that case, the general rules of the BGB apply. In the event of a disruption, § 642 BGB is particularly interesting here. It provides for a compensation claim for you as a contractor if the client neglects a necessary cooperation action and thereby delays acceptance. Unlike the claim for damages under § 6 Abs. 6 VOB/B, which requires fault on the part of the client, the compensation claim under § 642 BGB only requires the mere violation of the client’s duties. The cooperation obligations of the client – for example, the timely provision of plans or ensuring a clear construction site – are the crux here. If this cooperation is missing or is inadequate, it can trigger a construction disruption assessed under BGB rules. Often, the principles of the construction disruption according to VOB serve as good reference.Where does it hurt? The most common causes of construction disruptions uncovered.
A construction disruption according to VOB can really have many triggers. Finding out the exact cause is super important because it determines who is responsible and whether you have claims for more time or compensation. You have to distinguish clearly: Does the disruption come from the client, is it the weather, or are there other reasons? Only then can you correctly classify and report such a disruption. So take the time to carefully examine the circumstances of each disruption.
Disruptions caused by the client
Often, the responsibility for a construction disruption according to VOB lies in the hands of the client. Common examples include delayed or faulty plan deliveries, building permits that take their time, or client decisions that simply come too late. Also, changed or additional services – the beloved amendments – can significantly disrupt the construction process and cause a amendment management according to VOB/B-situation that is then classified as a construction disruption according to VOB construction disruption. Similarly, deficient pre-services from other trades, commissioned by the client, can result in you being unable to continue your work as planned. In all these cases, the rule is: Document precisely and immediately submit a disruption notification due to the disruption!
Weather-related disruptions as construction disruptions according to VOB.
Not every rainy day is automatically a construction disruption according to VOB. For the weather to count as a reason for a disruption, it must be unforeseeable and extraordinary – i.e., significantly more severe than expected at the time of the bid. VOB/B (§ 6 Abs. 2 Nr. 2) classifies such cases as grounds for a deadline extension. You, as the contractor, must provide proof that it is indeed extraordinary weather (i.e., events that may only occur every 10-15 years). This could be done through data from the German Weather Service. Extreme heat, torrential rain, or prolonged frost that render continuation of work impossible or unreasonable can constitute such a disruption. A precise documentation of the weather extremes and their impacts, preferably in the digital construction diary, is worth its weight in gold here.
Other reasons for a construction disruption
Besides disruptions caused by the client or the weather, there are other possible causes for a construction disruption according to VOBconstruction disruption. These include, for example, strikes and lockouts, whether in your own business or in others, if they directly impact the construction process. Also, force majeure – think of natural disasters or unforeseeable pandemics with government restrictions – can represent a disruption. Sometimes there are also disruptions caused by third parties, such as unexpected archaeological finds or old ordnance that halt construction progress. And don’t forget the construction site risk. If suddenly, entirely different soil conditions emerge than expected, and that is not your responsibility, it may necessitate an adjustment of construction execution. Each of these situations must be carefully examined and may require a disruption notification.The disruption notification: Here’s how to do it right and secure your claims!
The disruption notification – this is your most important tool as a contractor to secure your rights in the event of a construction disruption according to VOB disruption. Whether it actually works depends crucially on whether you comply with the formal requirements and whether the content is precise. A carefully formulated and timely notification informs your client and gives them the chance to eliminate the disruption. Mistakes in the disruption notification can be very costly and lead to the loss of claims – so please take this step seriously! A good construction daily report software can actually be a real help in this process.
- Understanding the disruption notification as a central instrument for legal security.
- Ensure formal requirements and the precise content of the notification.
- Inform the client in a timely manner to enable remedial actions.
- Avoid errors in the notification to prevent the loss of claims.
Formal requirements: immediacy, written form, addressee
The VOB/B sets clear guidelines for how a disruption notification in the case of a construction disruption according to VOB should be structured. It must be ‘immediate’ – meaning ‘without culpable delay’, so as soon as you notice or suspect that you are being hindered in your work. The written form is a must; you can do this by letter, fax, or even email, as long as you can prove receipt. Very importantly: The notification must go directly to the client . Just informing the architect or the construction management is often not enough, unless they are explicitly authorized to receive such statements. These formalities are the basis for ensuring that your disruption notification is also effective.
Minimum content requirements of a construction disruption notification
For your disruption notification to hit the mark and inform the client comprehensively in the case of a construction disruption according to VOB , a few things absolutely must be included. These include:
- Exact description of the disruption: What exactly is hindering you? Which works are affected? Where lies the cause of the disruption?
- Start and expected duration: Since when has the disruption existed and how long is it expected to last? A precise timeframe is important later for calculating extensions.
- Impact on the construction process: How does the disruption affect the planned construction process and your contractual deadlines? Are there even critical tasks affected?
- Possible cost impacts: A hint at possible additional costs is wise, even if you might not be able to quantify them immediately. This secures your future claims.
- Comprehensive documentation: Attach evidence! Photos, excerpts from the construction diary, or correspondence help substantiate the disruption and its causes.
The clearer and more detailed your depiction of the situation, the better misunderstandings can be avoided and a solid basis can be created for a constructive resolution of the situation.
Samples and software solutions for the disruption notification
Sure, the internet is overflowing with ‘disruption notification VOB template PDF’ or ‘disruption notification VOB template Word’. Such templates can be a first point of reference, but please: Never simply copy them! Each construction disruption according to VOB is unique and needs a notification tailored precisely to the situation on your construction site. An inappropriate or incomplete template can do more harm than good. Modern software solutions, such as the ones we develop here at Valoon GmbH, can assist you in creating and managing disruption notifications. They often offer structured input forms and a central repository for all documents. Still, they do not replace your own careful review and adaptation, especially when it comes to tricky disruption cases. Our software focuses on facilitating data collection and information flow, which of course also simplifies the documentation of a construction disruption according to VOB disruption.Notification is sent – and now? Your rights and obligations laid out clearly
Okay, the disruption notification due to a construction disruption according to VOB has been issued – and what now? At this point, both you as a contractor and your client have certain rights and obligations. These are crucial for how the project will proceed and how to minimize the negative consequences. Communicating and cooperating is often the best way to effectively resolve the issues arising from the disruption and avoid lengthy disputes. By knowing these regulations, you strengthen your position and can take the right steps.
Contractor obligations after the notification
Even if the disruption notification has been sent, it doesn’t mean that you, as a contractor in the event of a construction disruption according to VOB can sit back and relax. You have the duty to mitigate damages.This means you must do everything reasonable to keep the impact of the disruption as low as possible. This could mean, for instance, prioritizing other tasks if possible, or deploying your personnel and equipment sensibly elsewhere. Once the disruption has been resolved, you must resume work without culpable delay. Document the resumption of work accurately, preferably in the construction diary, to record the exact duration of the interruption due to the disruption. This proactive attitude is an important building block in dealing with a construction disruption according to VOB.
Contractor rights in case of a construction disruption
If you have properly notified a construction disruption according to VOB and are not at fault, you have various rights. The most important is the claim for extension of execution deadlines according to § 6 Abs. 2 VOB/B. How long the deadline is extended depends on the duration of the disruption, plus a fair allowance for the resumption of work and any delays into less favorable seasons. Additionally, depending on the contract and cause of the disruption, you may be entitled to damages (according to § 6 Abs. 6 VOB/B, if the client caused the disruption) or compensation (according to § 642 BGB, if the client is in acceptance delay). If the disruption lasts longer (usually over three months), under certain circumstances a special termination right can arise for both sides. To assert these rights, you need precise documentation of the construction disruption according to VOB and its consequences.
Client’s reactions and obligations
The client must also act after receiving a disruption notification. They must carefully review and respond to the notification. They can either accept the reported disruption, request further clarification or reasoned reject it.. No matter how they evaluate the issue, the client has an obligation to cooperate in removing the disruption if it comes from their area or if they can influence it. The aim should always be to eliminate the causes of the disruption as soon as possible, so that the construction progress is not further hampered. Constructive cooperation is key here to keep the impacts of the disruption minimal and to prevent escalation. The Mitwirkungspflicht, die Behinderung zu beseitigen, wenn sie aus seinem Bereich kommt oder er darauf Einfluss hat. Ziel sollte immer sein, die Ursachen der Störung so schnell wie möglich auszuräumen, damit der Baufortschritt nicht noch weiter leidet. Eine konstruktive Zusammenarbeit ist hier das A und O, um die Auswirkungen der Behinderung klein zu halten und eine Eskalation zu verhindern. Die construction project management plays an important role in keeping track.More time, more money? Here’s how to handle extensions and more during construction disruptions.
A construction disruption according to VOB costs not only time but often money as well. Correctly calculating the extensions and asserting claims for damages or compensation is tricky. Accurate knowledge of the legal foundations and comprehensive documentation is needed. Mistakes can quickly lead to significant financial losses. That’s why it is so important for you as a contractor to understand the mechanisms behind these claims in the event of a construction disruption according to VOB construction disruption and to substantiate your demands solidly.
Calculation of deadline extensions for construction disruptions according to VOB
How execution deadlines are extended in case of a construction disruption according to VOB is stated in § 6 Abs. 2 and Abs. 3 VOB/B. The new deadline is not simply the duration of the disruption. You must also include allowances for the resumption of work (i.e., setup times) and for potential postponements of work into less favorable seasons. If, for example, concrete work moves from summer to winter, longer drying times or additional protective measures may become necessary, extending the construction time. Calculating these allowances requires a detailed analysis of the construction process and the specific effects of the disruption. If multiple disruptions occur simultaneously, it gets more complicated. Then, it must be determined which disruption was really the cause of the delay. A detailed construction documentation documentation is absolutely essential here.
Claims for damages according to § 6 Abs. 6 VOB/B
If the client caused the disruption, you as a contractor can claim damages for your additional costs according to § 6 Abs. 6 VOB/B. This may include costs for idle personnel (standby costs), unused equipment, additional site setup, or increased material prices. You as a contractor must prove the incurred damage and its extent construction disruption according to VOB verschuldet hat, können Sie als Auftragnehmer nach § 6 Abs. 6 VOB/B Schadensersatz für Ihre Mehrkosten fordern. Das können zum Beispiel Kosten für Personal sein, das Däumchen dreht (Vorhaltekosten), ungenutzte Geräte, zusätzliche Baustelleneinrichtung oder gestiegene Materialpreise. Sie als Auftragnehmer müssen den entstandenen Schaden und seine Höhe with documentation.A detailed documentation of the additional costs, for instance, through detailed cost statements and receipts, is therefore a must. It is also important that you meet your duty to mitigate damage : You must try to keep the damage as minimal as possible. Making claims for damages in such a disruption is often a case for a legal expert.
Compensation according to § 642 BGB: Requirements and calculations
If there is a construction disruption, because the client violated a duty to cooperate (for example, releasing plans too late) and thus causes a delay in acceptance, you as a contractor can demand reasonable compensation according to § 642 BGB. This also applies if the VOB/B was not agreed or if the conditions for damages are not met. The requirements for a compensation claim are that you have offered your service and the disruption has been reported (or was obvious). The basis for calculating the compensation is your original contractual calculation.You can demand payment for services not rendered, but you must account for any savings in expenses. Here too, the burden of proof for the requirements and the amount of compensation lies with you. The OLG Celle clarified important points in its ruling of 04.03.2020 – 7 U 334/18. construction disruption bei Ihnen. Das OLG Celle hat dazu im Urteil vom 04.03.2020 – 7 U 334/18 wichtige Punkte klargestellt.Talking is gold, documentation is platinum: Cleverly avoid conflicts in case of construction disruptions.
A construction disruption according to VOB does not necessarily mean that there will be a fallout. On the contrary: With proactive, open communication and seamless, transparent documentation, many problems can be identified, tackled, and resolved early on. Consider the disruption notification not as a declaration of war but as a necessary tool to inform everyone and coordinate the next steps. A strategic approach to the situation can even strengthen cooperation and help successfully complete the construction project despite the disruption. This is exactly where we at Valoon GmbH come into play with our solutions: We want to help you master these processes with simple and efficient digital tools.
See the construction disruption notification as an opportunity for cooperation.
Timely and factually informing the client about a looming or already occurring construction disruption according to VOB is the first step to smoothing things over. Instead of postponing the notification until the last moment, you as a contractor should view it as an opportunity to bring the client on board and find a solution together. An open and transparent communication about the causes, expected duration, and possible impacts of the disruption builds trust. This way, the client can also take action and implement measures. The disruption notification thus serves not only to secure your rights but also as a basis for joint solutions to minimize the negative consequences of the disruption for the entire project. A well-functioning defect management can also be very helpful here.
Seamless documentation as the key to success.
It cannot be said often enough: A detailed and seamless documentation is essential in the case of a construction disruption according to VOB disruption. It lays the foundation for asserting claims for more time and money and serves as evidence in case of disputes. Document not only the disruption notification itself but also everything related to it: the cause of the disruption, the exact duration, which works are affected, what you have done to mitigate damage, all communication with the client, and of course the resulting additional costs. A comprehensive audit trail, i.e., a traceable chain of all events, is crucial here. Modern software solutions, such as a construction daily report software or specialized apps for construction documentation, can provide valuable services in this regard. They help in systematically capturing and centrally storing all relevant info. This makes everything more traceable, which is worth its weight in gold in such situations.
Avoid typical mistakes and seek timely advice.
When filling out and handling disruption notifications in the context of a construction disruption according to VOB unfortunately, mistakes often occur that can have nasty consequences. These include late notifications, insufficient justifications, the wrong address, or incomplete documentation. To avoid such mistakes, it’s important that you know the formal and content-related requirements precisely and implement them consistently. Another good strategy to avoid mistakes: Seek legal advice early on. An attorney specializing in construction law can evaluate your specific situation, assist you in formulating the notification, and recommend the strategically best steps to optimally protect your rights in the event of a disruption. This investment can quickly pay off by preventing expensive disputes.. Ein Anwalt, der sich auf Baurecht spezialisiert hat, kann Ihre spezielle Situation bewerten, Ihnen bei der Formulierung der Anzeige helfen und Ihnen die strategisch besten Schritte empfehlen, um Ihre Rechte im Falle einer Behinderung optimal zu schützen. Diese Investition kann sich schnell bezahlt machen, indem sie teure Streitereien verhindert.Learned from practice: Real cases, real solutions for construction disruptions.
The theory to construction disruption according to VOB is nice and well, but how does it all look in the rough construction practice? This is often a completely different ball game. Based on typical case studies, we want to look at the potential consequences of disruptions and why correct action is so important. These examples show how varied the causes of a disruption can be and which preventive measures and response strategies have proven effective in everyday life. Our goal is to learn from these ‘lessons learned’ so that your future projects are better equipped against disturbances and you can react a construction disruption according to VOB more effectively.
Typical scenarios of construction disruption and their management
Unfortunately, in daily construction life, there are many situations that can trigger a construction disruption according to VOB disruption. A true classic is delays due to missing or untimely building permits – these can often paralyze the entire project start. Here, the client is clearly in charge, and for you as the contractor, an early disruption notice is indispensable. Another frequent annoyance is disruptions due to deficient or incomplete planning. If execution plans are missing, contradictory, or need to be changed, this can lead to significant standstill and re-planning – a clear construction disruption according to VOB. Also, weather-related disruptions, exceeding the normal level (think of extreme cold periods that make concrete work impossible), must be documented and announced precisely. In all these cases, quick reaction and detailed recording of all occurrences are crucial to securing your claims in the event of such a disruption. A good digital defect management can help uncover planning errors at an early stage.
Lessons learned: optimizing prevention and response
When looking at past cases of construction disruption according to VOB disruption, a lot can be learned for the future. A very important insight is: Careful and forward-looking planning on the part of the client is invaluable to minimize typical causes of disruption such as late plans or permits from the outset. For you as the contractor, it is super important to establish a solid system for the seitens des Auftraggebers ist Gold wert, um typische Behinderungsursachen wie späte Pläne oder Genehmigungen von vornherein zu minimieren. Für Sie als Auftragnehmer ist es superwichtig, ein solides System für die construction documentation and writing the daily construction report. This way, you can respond quickly with solid facts in the case of a disruption. What has proven effective on the construction site? Clear communication channels, regular construction meetings, and proactive risk management. If potential disruption factors are recognized early and emergency plans are at hand, the impact of an actual disruption can often be reduced. In the end, experience shows time and again: Collaborative partnerships and the willingness to find a solution together often yield more than stubbornly insisting on one’s own standpoint. aufzubauen. So können Sie im Fall einer Behinderung schnell und mit handfesten Fakten reagieren. Was sich auf der Baustelle bewährt hat? Klare Kommunikationswege, regelmäßige Baubesprechungen und ein proaktives Risikomanagement. Wenn man mögliche Störfaktoren frühzeitig erkennt und Notfallpläne in der Schublade hat, lassen sich die Auswirkungen einer tatsächlichen Behinderung oft reduzieren. Am Ende zeigt die Erfahrung immer wieder: Eine partnerschaftliche Zusammenarbeit und der Wille, gemeinsam eine Lösung zu finden, bringen oft mehr als stures Beharren auf dem eigenen Standpunkt.Managing construction disruptions: Your roadmap for smoother construction projects
Phew, the construction disruption according to VOB – quite a complex topic, right? But don’t worry, with the right knowledge and the right tools, you can get a grip on it. A proper notice, comprehensive documentation, and open discussions are the key pillars to protecting your rights and successfully completing projects even in the face of disruptions. We do not aim to present disruption as an evil that must be endured. Instead, view it as a challenge that also offers opportunities – for example, to improve collaboration and your own processes. We at Valoon GmbH want to help you exactly with that: optimizing your communication and documentation processes so that you can maintain clarity and act quickly and efficiently, even in the face of such challenges. Use the tips from this article to prepare your construction projects for the future! construction disruption according to VOB als ein Übel darzustellen, das man eben ertragen muss. Sehen Sie es lieber als eine Herausforderung, die auch Chancen bietet – zum Beispiel, um die Zusammenarbeit und die eigenen Prozesse zu verbessern. Wir bei Valoon GmbH möchten Ihnen genau dabei helfen: Ihre Kommunikations- und Dokumentationsprozesse so zu optimieren, dass Sie auch bei einer solchen Herausforderung den Durchblick behalten und schnell und effizient handeln können. Nutzen Sie die Tipps aus diesem Artikel, um Ihre Bauprojekte fit für die Zukunft zu machen!
Key insights and the role of digitalization
So let’s summarize: The disruption notice is your trump card, to secure your rights as a contractor in case of a construction disruption according to VOB disruption. If you use it timely and correctly, supported by comprehensive documentation, you will have a strong basis for successful negotiations for more time and financial compensation. Digitalization plays to our advantage here: Software solutions for the construction documentation, the digital construction diary and writing the defect management, like those we offer here at Valoon GmbH, make capturing, structuring, and exchanging information much easier. This not only saves administrative effort but also makes everything more transparent and traceable – particularly invaluable in the case of such disruptions. Utilizing such tools can significantly help avoid disputes and find a fair solution for all.
Future developments and opportunities
The construction industry is constantly evolving, driven by new technologies and changing legal frameworks. In the future, Building Information Modeling (BIM), artificial intelligence, and automated processes will play an even greater role. These technologies can help reduce planning errors, better coordinate construction processes, thereby reducing the risk of a construction disruption according to VOB disruption. Also, the legal basis, such as the VOB/B, is continuously evolving. It remains important to stay updated and seize the opportunities offered by digitalization to proactively address the challenges of construction delays and sustainably improve efficiency and quality in construction. If you’re curious about how we at Valoon GmbH can support you in ensuring your project documentation and communication are top-notch, so you’re well-prepared for potential disruptions, just construction disruption according to VOB contact us for personalized advice . We look forward to hearing from you!What is a construction disruption according to VOB, and why is it important for my construction company?
A disruption occurs when unavoidable circumstances hinder you as a contractor from timely or scheduled construction execution. It is crucial because it can
A construction disruption according to VOB establish claims for extensions and possibly damages , provided the VOB/B is part of the contract and you act correctly. Do I also need to file a disruption notice if the client is already aware of the problem?
Yes, generally always.
The VOB/B requires a Die VOB/B fordert eine immediate written notification. Relying solely on the client’s knowledge is risky and could lead to the loss of your claims, unless the disruption is absolutely obvious and its effects are also clear to the client – a risky exception.
What information must a disruption notice absolutely contain?
An effective disruption notice must clearly describe the cause of the disruption, the affected work, the start, and the expected duration, as well as the impact on the construction process. A precise documentation is crucial. What happens if I do not or too late report a construction disruption?
Was passiert, wenn ich eine Baubehinderung nicht oder zu spät anzeige?
If you do not report a construction disruption immediately and in writing, you risk losing your claims to an extension of construction time and possible financial compensations or damages . Timely reporting is a core obligation. Does every bad weather count as a disruption according to VOB?No.
Zählt jedes schlechte Wetter als Baubehinderung nach VOB?
Unpredictable and extraordinary weather conditions Nur , which could not be anticipated at the time of tender submission (e.g., events that occur only every 10-15 years), are considered a disruption. Normal bad weather is to be taken into account in the construction process.What claims do I have as a contractor in the case of a legitimate disruption?
Welche Ansprüche habe ich als Auftragnehmer bei einer berechtigten Baubehinderung?
In the case of a legitimate disruption, you primarily have a right to a extension of execution deadlines. Depending on the cause and contractual basis, claims for damages (according to § 6 Abs. 6 VOB/B) or compensation (according to § 642 BGB) may also arise.
How can software help me with a disruption?
Software like Valoon simplifies the quick and verifiable documentation of disruptions directly on-site, for example via messenger. It supports the comprehensive documentation (photos, reports) and the creation of formal notices, making it easier to assert your claims and improving communication.
What is the difference between damages (VOB/B) and compensation (BGB)?
Damages under § 6 Abs. 6 VOB/B require the client’s fault for the disruption and cover specific additional costs. The compensation under § 642 BGB applies in cases of the client’s default of acceptance (failure to cooperate) and is based on contractual calculations, even without fault.
